Full Text of HB5412 102nd General Assembly
HB5412 102ND GENERAL ASSEMBLY |
| | 102ND GENERAL ASSEMBLY
State of Illinois
2021 and 2022 HB5412 Introduced 1/31/2022, by Rep. Marcus C. Evans, Jr. SYNOPSIS AS INTRODUCED: |
| |
Amends the Illinois Wage Payment and Collection Act. Provides that, for all contracts entered into on or after July 1, 2022, a primary contractor making or taking a contract in the State for the erection, construction, alteration, or repair of a building, structure, or other private work in the State, shall assume, and is liable for, any debt owed to a claimant incurred pursuant to the Act by a subcontractor at any tier acting under, by, or for the primary contractor for the wage claimant's performance of labor included in the subject of the contract between the primary contractor and the owner. Provides exemption from liability for a property owner who acts as a primary contractor related to the erection, construction, alteration, or repair of his or her primary residence. Defines terms. Provides that the primary contractor's liability under the new provisions shall extend only to any unpaid wages or fringe or other benefit payments or contributions, including interest owed, penalties assessed by the Department,
and reasonable attorney's fees, but shall not extend to
liquidated damages. Provides that a primary contractor or any other person shall not evade or commit any act that negates the requirements of the new provisions. Provides that the obligations and remedies provided in the new provisions shall be in addition to any obligations and remedies otherwise provided by law, except that nothing in the new provisions shall be construed to impose liability on a primary contractor for anything other than unpaid wages, fringe or other benefit payment contributions, penalties assessed by the Department of Labor, interest owed, and reasonable attorney's fees. Provides that claims brought pursuant to the new provisions shall be done so in accordance with provisions concerning violations of the Act.
|
| |
| | A BILL FOR |
|
| | | HB5412 | | LRB102 25322 SPS 34596 b |
|
| 1 | | AN ACT concerning employment.
| 2 | | Be it enacted by the People of the State of Illinois,
| 3 | | represented in the General Assembly:
| 4 | | Section 5. The Illinois Wage Payment and Collection Act is | 5 | | amended by adding Section 13.5 as follows: | 6 | | (820 ILCS 115/13.5 new) | 7 | | Sec. 13.5. Primary contractor responsibility for wage
| 8 | | claims in construction industry. | 9 | | (a) For all contracts entered into on or after July 1,
| 10 | | 2022, a primary contractor making or taking a contract in the
| 11 | | State for the erection, construction, alteration, or repair of
| 12 | | a building, structure, or other private work in the State,
| 13 | | shall assume, and is liable for, any debt owed to a
claimant | 14 | | under this Section or to a third party on a wage claimant's | 15 | | behalf incurred pursuant to this Act by a subcontractor at
any | 16 | | tier acting under, by, or for the primary contractor for
the | 17 | | wage claimant's performance of labor included in the
subject | 18 | | of the contract between the primary contractor and the
owner. | 19 | | This Section does not apply to work performed by a
contractor | 20 | | of the State, a special district, a city, a county,
or any | 21 | | political subdivision of the State. | 22 | | (b) As used in this Section: | 23 | | "Construction" means building, altering, repairing, |
| | | HB5412 | - 2 - | LRB102 25322 SPS 34596 b |
|
| 1 | | improving, or demolishing any structure or building or making | 2 | | improvements of any kind to real property. | 3 | | "Primary contractor" means a contractor that has a direct
| 4 | | contractual relationship with a property owner. "Primary
| 5 | | contractor" may have the same meaning as a "general
| 6 | | contractor", "prime contractor", or "construction manager". A | 7 | | property owner
who acts as a primary contractor related to the | 8 | | erection,
construction, alteration, or repair of his or her | 9 | | primary
residence
shall be exempt from liability under this
| 10 | | Section. | 11 | | "Private work" means any erection, construction,
| 12 | | alteration, or repair of a building, structure, or other work. | 13 | | "Subcontractor" means a contractor that has a contractual
| 14 | | relationship with the primary contractor or with another
| 15 | | subcontractor at any tier, who furnishes any goods or services
| 16 | | in connection with the contract between the primary contractor
| 17 | | and the property owner, but does not include contractors who
| 18 | | solely provide goods and transport of such goods related to
| 19 | | the contract. | 20 | | (c) The primary contractor's liability under this Section
| 21 | | shall extend only to any unpaid wages or fringe or other | 22 | | benefit payments or contributions, including interest owed, | 23 | | penalties assessed by the Department,
and reasonable | 24 | | attorney's fees, but shall not extend to
liquidated damages. | 25 | | (d) A primary contractor or any other person shall not
| 26 | | evade or commit any act that negates the requirements of this
|
| | | HB5412 | - 3 - | LRB102 25322 SPS 34596 b |
|
| 1 | | Section. Except as otherwise provided in a contract between
| 2 | | the primary contractor and the subcontractor, the
| 3 | | subcontractor shall indemnify the primary contractor for any
| 4 | | wages, fringe or other benefit payments or contributions, | 5 | | damages, interest, penalties, or attorney's fees owed
as a | 6 | | result of the subcontractor's failure to pay wages or fringe | 7 | | or other benefit payments or contributions
as provided in this | 8 | | Section, unless
the subcontractor's failure to pay was due to | 9 | | the
primary contractor's failure to pay moneys due to the
| 10 | | subcontractor in accordance with the terms of their
| 11 | | contractual relationship. | 12 | | (e) The obligations and remedies provided in this Section
| 13 | | shall be in addition to any obligations and remedies otherwise
| 14 | | provided by law, except that nothing in this Section shall be
| 15 | | construed to impose liability on a primary contractor for
| 16 | | anything other than unpaid wages, fringe or other benefit | 17 | | payments or contributions, penalties assessed by the | 18 | | Department,
interest owed, and
reasonable attorney's fees. | 19 | | (f) Claims brought pursuant to this Section shall be done
| 20 | | so in accordance with Section 11 and 11.5 of this Act. Nothing | 21 | | in this Section shall be construed to provide a third party | 22 | | with the right to file a complaint with the Department | 23 | | alleging violation of this Section.
|
|